Terms & Conditions

By using https://launchapp.website or engaging LaunchApp ("we", "us") for services, you agree to these terms. If you do not agree with them, please do not use the site or engage us.

Where a signed proposal, quotation or contract exists between us, that document governs the engagement and these terms fill in anything it does not cover.

We provide mobile application development, website development, UI/UX design, custom software development and related launch and maintenance services.

What is included in your project is defined in the written scope we agree before work begins. Anything not listed in that scope is not included, and will be quoted separately as a change request.

Quotations are based on the requirements you describe at the time of quoting and remain valid for 30 days unless stated otherwise.

If requirements change after work has started — new features, redesigned screens, additional integrations — we will tell you the effect on cost and timeline in writing, and proceed only once you approve it. We will never invoice you for work you did not approve.

Projects are billed against milestones agreed in the proposal. A milestone becomes payable when the work described in it is delivered for your review.

• Invoices are payable within the period stated on the invoice.
• Work on subsequent milestones may be paused while an invoice remains unpaid beyond its due date.
• Third-party costs — app store developer accounts, hosting, domains, paid APIs, licensed assets — are billed at cost and are your responsibility unless the proposal says otherwise.
• All fees exclude applicable taxes unless expressly stated.

To keep a project on schedule, you agree to:

• Provide content, assets, branding and access credentials in reasonable time.
• Nominate one person who can give decisions and approvals on your behalf.
• Respond to review requests within the timeframe set in the project plan.
• Ensure you hold the rights to any content, logos or material you give us to use.

Delays caused by outstanding feedback, content or approvals move the delivery timeline accordingly.

Each design and development milestone includes a reasonable number of revision rounds, stated in the proposal. Revisions within the agreed scope are included. Requests that change the agreed direction after approval are treated as change requests and quoted separately.

On receipt of final payment, ownership of the source code, designs and project-specific assets we create for you transfers to you. You are free to modify them or engage another developer at any point afterwards.

We retain ownership of generic components, libraries, tooling and know-how that pre-existed your project or that we use across clients. You receive a perpetual licence to use these as part of your delivered product.

Third-party software, fonts and libraries remain subject to their own licences, which we will identify where relevant.

We would like to reference completed work in our portfolio. We will ask you first, and we will not publish screenshots, client names or project details without your permission. If you prefer the engagement to remain confidential, tell us and it will.

We provide one month of free support after launch, covering defects in the delivered work — things that do not behave as the agreed scope specified.

This support period does not cover:

• New features or changes to agreed behaviour.
• Problems caused by changes made by you or a third party after handover.
• Failures of third-party services, hosting or APIs outside our control.
• Updates required by new operating system or platform releases after delivery.

Ongoing maintenance beyond this period is available as a separate arrangement.

We treat your business information, ideas and project details as confidential and will not disclose them to third parties except where necessary to deliver the work or where required by law. We are happy to sign a mutual non-disclosure agreement before detailed discussions.

To the extent permitted by law, our total liability arising from an engagement is limited to the fees you have paid us for that engagement.

We are not liable for indirect or consequential losses, including loss of profit, revenue, data or business opportunity. Nothing in these terms limits liability that cannot be limited by law.

Either party may end an engagement in writing. Work completed and in progress up to the cancellation date is payable. Refunds are covered by our Refund Policy.

The content of this website is provided for information. We aim to keep it accurate but do not warrant that it is complete or current at all times.

Text, images, code and design on this website are owned by LaunchApp and may not be copied or republished without permission.

These terms are governed by the laws of India. Disputes will be subject to the jurisdiction of the courts of India, save that we will always attempt to resolve any disagreement directly and in good faith first.

Questions about these terms can be sent to hadost7@gmail.com.